Terms & Conditions
I. Purchase, II. Sale
I. TERMS AND CONDITIONS OF PURCHASE
Business Day: a day (other than a Saturday, Sunday or public holiday) when banks in London are open for business.
Conditions: the terms and conditions set out in this document as amended from time to time in accordance with clause 16.4.
Contract: the contract between the Customer and the Supplier for the sale and purchase of the Goods in accordance with these Conditions.
Customer: Innovative ThermoAnalytic Instruments Limited incorporated and registered in England and Wales with company number 07425277 whose registered office is at Suite 2, 1 Leonard Place, Westerham Rd, Keston BR2 6HQ.
Delivery date: the date specified in the Order.
Delivery Location: the address for delivery of Goods as set out in the Order.
Goods: the goods (or any part of them) set out in the Order.
Intellectual Property Rights: patents, utility models, rights to inventions, copyright and neighbouring and related rights, trademarks and service marks, business names and domain names, rights in get-up and trade dress, goodwill and the right to sue for passing off or unfair competition, rights in designs, database rights, rights to use, and protect the confidentiality of, confidential information (including know-how and trade secrets), and all other intellectual property rights, in each case whether registered or unregistered and including all applications and rights to apply for and be granted, renewals or extensions of, and rights to claim priority from, such rights and all similar or equivalent rights or forms of protection which subsist or will subsist now or in the future in any part of the world.
Invention: any idea, discovery, development, improvement or innovation made by the Supplier in the provision of the Goods, whether or not capable of registration, and whether or not recorded in any medium.
Order: the Customer's order for the Goods, as set out in the Customer's purchase order form.
Specification: any specification for the Goods, including any related plans and drawings that is agreed in writing by the Customer and the Supplier.
Supplier: the person or firm from whom the Customer purchases the Goods.
Works: all records, reports, documents, papers, drawings, designs, transparencies, photos, graphics, logos, typographical arrangements, software, and all other materials in whatever form, including but not limited to hard copy and electronic form, prepared by the Supplier in the provision of the Goods.
(a) a reference to a statute or statutory provision is a reference to such statute or provision as amended or re-enacted. A reference to a statute or statutory provision includes any subordinate legislation made under that statute or statutory provision, as amended or re-enacted;
(b) any phrase introduced by the terms including, include, in particular or any similar expression shall be construed as illustrative and shall not limit the sense of the words preceding those terms; and
(c) a reference to writing or written includes faxes and emails.
2. Basis of contract
2.1 These Conditions apply to the Contract to the exclusion of any other terms that the Supplier seeks to impose or incorporate, or which are implied by trade, custom, practice or course of dealing.
2.2 The Order constitutes an offer by the Customer to purchase the Goods in accordance with these Conditions.
2.3 The Order shall be deemed to be accepted on the earlier of:
(a) the Supplier issuing a written acceptance of the Order; and
(b) the Supplier doing any act consistent with fulfilling the Order,
at which point the Contract shall come into existence.
2.4 The Supplier waives any right it might otherwise have to rely on any term endorsed upon, delivered with or contained in any documents of the Supplier that is inconsistent with these Conditions.
3. The goods
3.1 The Supplier shall ensure that the Goods shall:
(a) correspond with their description and any applicable Specification;
(b) be of satisfactory quality (within the meaning of the Sale of Goods Act 1979, as amended) and fit for any purpose held out by the Supplier or made known to the Supplier by the Customer expressly or by implication, and in this respect the Customer relies on the Supplier's skill and judgement;
(c) where they are manufactured products, be free from defects in design, material and workmanship and remain so for 12 months after delivery; and
(d) comply with all applicable statutory and regulatory requirements relating to the manufacture, labelling, packaging, storage, handling and delivery of the Goods.
3.2 The Supplier shall ensure that at all times it has and maintains all the licences, permissions, authorisations, consents and permits that it needs to carry out its obligations under the Contract.
3.3 The Customer may inspect and test the Goods at any time before delivery. The Supplier shall remain fully responsible for the Goods despite any such inspection or testing and any such inspection or testing shall not reduce or otherwise affect the Supplier's obligations under the Contract.
3.4 If following such inspection or testing the Customer considers that the Goods do not conform or are unlikely to comply with the Supplier's undertakings at clause 3.1, the Customer shall inform the Supplier and the Supplier shall immediately take such remedial action as is necessary to ensure compliance.
3.5 The Customer may conduct further inspections and tests after the Supplier has carried out its remedial actions.
4.1 The Supplier shall ensure that:
(a) the Goods are properly packed and secured in such manner as to enable them to reach their destination in good condition;
(b) each delivery of the Goods is accompanied by a delivery note which shows the date of the Order, the Order number (if any), the type and quantity of the Goods (including the code number of the Goods, where applicable), special storage instructions (if any) and, if the Goods are being delivered by instalments, the outstanding balance of Goods remaining to be delivered; and
(c) if the Supplier requires the Customer to return any packaging material to the Supplier, that fact is clearly stated on the delivery note. Any such packaging material shall be returned to the Supplier at the cost of the Supplier.
4.2 The Supplier shall deliver the Goods:
(a) on the Delivery Date;
(b) at the Delivery Location; and
(c) during the Customer's normal business hours, or as instructed by the Customer.
4.3 Delivery of the Goods shall be completed on the completion of unloading the Goods at the Delivery Location.
4.4 The Supplier shall not deliver the Goods in instalments without the Customer's prior written consent. Where it is agreed that the Goods are to be delivered by instalments, they may be invoiced and paid for separately. However, failure by the Supplier to deliver any one instalment on time or at all or any defect in an instalment shall entitle the Customer to the remedies set out in clause 5.
5.1 If the Goods are not delivered on the Delivery Date, or do not comply with the undertakings set out in clause 3.1, then, without limiting any of its other rights or remedies, and whether or not it has accepted the Goods, the Customer may exercise any one or more of the following remedies :
(a) to terminate the Contract;
(b) to reject the Goods (in whole or in part) and return them to the Supplier at the Supplier's own risk and expense;
(c) to require the Supplier to repair or replace the rejected Goods, or to provide a full refund of the price of the rejected Goods (if paid);
(d) to refuse to accept any subsequent delivery of the Goods which the Supplier attempts to make;
(e) to recover from the Supplier any costs incurred by the Customer in obtaining substitute goods from a third party; and
(f) to claim damages for any other costs, loss or expenses incurred by the Customer which are in any way attributable to the Supplier's failure to carry out its obligations under the Contract.
5.2 These Conditions shall apply to any repaired or replacement Goods supplied by the Supplier.
5.3 The Customer's rights and remedies under these Conditions are in addition to its rights and remedies implied by statute and common law.
6. Title and risk
Title and risk in the Goods shall pass to the Customer on completion of delivery.
7. Price and payment
7.1 The price of the Goods shall be the price set out in the Order, or, if no price is quoted, the price set out in the Supplier's published price list in force as at the date the Contract came into existence.
7.2 The price of the Goods:
(a) excludes amounts in respect of value added tax (VAT), which the Customer shall additionally be liable to pay to the Supplier at the prevailing rate, subject to the receipt of a valid VAT invoice; and
(b) includes the costs of packaging, insurance and carriage of the Goods.
7.3 No extra charges shall be effective unless agreed in writing with the Customer.
7.4 The Supplier may invoice the Customer for price of the Goods plus VAT at the prevailing rate (if applicable) on or at any time after the completion of delivery. The Supplier shall ensure that the invoice includes the date of the Order, the invoice number, the Supplier's VAT registration number, and any supporting documents that the Customer may reasonably require.
7.5 The Customer shall pay correctly rendered invoices within 30 days of receipt of the invoice. Payment shall be made to the bank account nominated in writing by the Supplier.
7.6 If a party fails to make any payment due to the other under the Contract by the due date for payment, then the defaulting party shall pay interest on the overdue amount at the rate of 2% per annum above the Bank of England's base rate from time to time. Such interest shall accrue on a daily basis from the due date until actual payment of the overdue amount, whether before or after judgment. The defaulting party shall pay the interest together with the overdue amount. This clause shall not apply to payments the defaulting party disputes in good faith.
7.7 The Customer may at any time, without limiting any of its other rights or remedies, set off any liability of the Supplier to the Customer against any liability of the Customer to the Supplier.
8. Customer materials
8.1 The Supplier acknowledges that all materials, equipment and tools, drawings, Specifications, and data supplied by the Customer to the Supplier (Customer Materials) and all rights in the Customer Materials are and shall remain the exclusive property of the Customer. The Supplier shall keep the Customer Materials in safe custody at its own risk, maintain them in good condition until returned to the Customer, and not dispose or use the same other than in accordance with the Customer's written instructions or authorisation.
8.2 The Supplier will promptly on request return to the Customer all and any Customer Materials in its possession and no copies shall be kept.
9. Intellectual Property
9.1 The Supplier shall notify the Customer in writing full details of all Inventions promptly on their creation and all existing and future Intellectual Property Rights in the Works.
9.2 The Supplier hereby assigns to the Customer all existing and future Intellectual Property Rights in the Works and the Inventions and all materials embodying these rights to the fullest extent permitted by law. Insofar as they do not vest automatically by operation of law or under this agreement, the Supplier holds legal title in these rights and inventions on trust for the Customer.
10.1 The Supplier shall keep in strict confidence all technical or commercial know-how, specifications, inventions, processes or initiatives which are of a confidential nature and have been disclosed to the Supplier by the Customer or its agents, and any other confidential information concerning the Customer's business or its products which the Supplier may obtain. The Supplier shall restrict disclosure of such confidential material to such of its employees as need to know the same for the purpose of discharging the Supplier's obligations to the Customer and shall ensure that such employees are subject to obligations of confidentiality corresponding to those which bind the Supplier.
10.2 All materials, equipment, tools, copyright, rights in designs and any other Intellectual Property Rights in all drawings, specifications and data supplied by the Customer to the Supplier shall at all times be and remain the exclusive property of the Customer, and shall be held by the Supplier in safe custody at its own risk and maintained and kept in good condition by the Supplier until returned to the Customer, and shall not be disposed or used other than in accordance with the Customer's written instructions or authorisation. The Supplier shall return all copies of any such material to the Customer immediately on the Customer's first written request.
10.3 This clause 10 shall survive the termination of the Contract, however arising.
11.1 The Supplier shall keep the Customer indemnified against all liabilities, costs, expenses, damages and losses (including but not limited to any direct, indirect or consequential losses, loss of profit, loss of reputation and all interest, penalties and legal costs (calculated on a full indemnity basis) and all other reasonable professional costs and expenses) suffered or incurred by the Customer as a result of or in connection with:
(a) any claim made against the Customer for actual or alleged infringement of a third party's intellectual property rights arising out of or in connection with the supply or use of the Goods, to the extent that the claim is attributable to the acts or omissions of the Supplier, its employees, agents or subcontractors;
(b) any claim made against the Customer by a third party for death, personal injury or damage to property arising out of or in connection with defects in Goods, to the extent that the defects in the Goods are attributable to the acts or omissions of the Supplier, its employees, agents or subcontractors; and
(c) any claim made against the Customer by a third party arising out of or in connection with the supply of the Goods, to the extent that such claim arises out of the breach, negligent performance or failure or delay in performance of the Contract by the Supplier, its employees, agents or subcontractors.
11.2 This clause 11 shall survive termination of the Contract.
The Supplier shall maintain in force, with a reputable insurance company, professional indemnity insurance, product liability insurance and public liability insurance to cover the liabilities that may arise under or in connection with the Contract, and shall, on the Customer's request, produce both the insurance certificate giving details of cover and the receipt for the current year's premium in respect of each insurance.
13. Compliance with relevant laws and policies
13.1 In performing it obligations under the Contract, the Supplier shall comply with all applicable laws, statutes, regulations and codes from time to time in force.
13.2 The Customer may immediately terminate the Contract for any breach of clause 13.
14.1 The Customer may terminate the Contract in whole or in part at any time before delivery with immediate effect by giving the Supplier written notice, whereupon the Supplier shall discontinue all work on the Contract. The Customer shall pay the Supplier fair and reasonable compensation for any work in progress on the Goods at the time of termination, but such compensation shall not include loss of anticipated profits or any consequential loss.
14.2 Without limiting its other rights or remedies, the Customer may terminate the Contract with immediate effect by giving written notice to the Supplier if:
(a) the Supplier commits a material breach of any term of the Contract and (if such a breach is remediable) fails to remedy that breach within 14 days of that party being notified in writing to do so;
(b) the Supplier takes any step or action in connection with its entering administration, provisional liquidation or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business or, if the step or action is taken in another jurisdiction, in connection with any analogous procedure in the relevant jurisdiction;
(c) the Supplier takes any step or action in connection with the Supplier being made bankrupt, entering any composition or arrangement with his creditors, having a receiver appointed to any of his assets, or ceasing to carry on business or, if the step or action is taken in another jurisdiction, in connection with any analogous procedure in the relevant jurisdiction;
(d) the Supplier suspends, or threatens to suspend, or ceases or threatens to cease to carry on all or a substantial part of its business; or
(e) the Supplier's financial position deteriorates to such an extent that in the Customer's opinion the Supplier's capability to adequately fulfil its obligations under the Contract has been placed in jeopardy.
14.3 Termination of the Contract, however arising, shall not affect any of the parties' rights and remedies that have accrued as at termination.
14.4 Clauses that expressly or by implication survive termination of the Contract shall continue in full force and effect.
15. Force majeure
Neither party shall be in breach of the Contract nor liable for delay in performing, or failure to perform, any of its obligations under it if such delay or failure results from an event, circumstance or cause beyond its reasonable control. If the period of delay or non-performance continues for 30 days, the party not affected may terminate this Contract by giving 14 days' written notice to the affected party.
16.1 Assignment and other dealings
(a) The Customer may at any time assign, transfer, mortgage, charge, subcontract or deal in any other manner with any or all of its rights or obligations under the Contract.
(b) The Supplier may not assign, transfer, mortgage, charge, declare a trust over or deal in any other manner with any or all of its rights or obligations under the Contract without the prior written consent of the Customer.
16.2 Subcontracting. The Supplier may not subcontract any or all of its rights or obligations under the Contract without the prior written consent of the Customer. If the Customer consents to any subcontracting by the Supplier, the Supplier shall remain responsible for all the acts and omissions of its subcontractors as if they were its own.
16.3 Entire agreement. This Contract constitutes the entire agreement between the parties and supersedes and extinguishes all previous agreements, promises, assurances, warranties, representations and understandings between them, whether written or oral, relating to its subject matter.
16.4 Variation. Except as set out in these Conditions, no variation of the Contract, including the introduction of any additional terms and conditions, shall be effective unless it is agreed in writing and signed by the Customer.
16.5 Waiver. Except as set out in clause 2.4, a waiver of any right or remedy is only effective if given in writing and shall not be deemed a waiver of any subsequent breach or default. A delay or failure to exercise, or the single or partial exercise of, any right or remedy shall not:
(a) waive that or any other right or remedy; or
(b) prevent or restrict the further exercise of that or any other right or remedy.
16.6 Severance. If any provision or part-provision of the Contract is or becomes invalid, illegal or unenforceable, it shall be deemed modified to the minimum extent necessary to make it valid, legal and enforceable. If such modification is not possible, the relevant provision or part-provision shall be deemed deleted. Any modification to or deletion of a provision or part-provision under this clause shall not affect the validity and enforceability of the rest of the Contract.
(a) Any notice or other communication given to a party under or in connection with the Contract shall be in writing, addressed to that party at its registered office (if it is a company) or its principal place of business (in any other case) or such other address as that party may have specified to the other party in writing in accordance with this clause, and shall be delivered personally, or sent by pre-paid first class post or other next working day delivery service, commercial courier, fax or email.
(b) A notice or other communication shall be deemed to have been received: if delivered personally, when left at the address referred to in clause 16.7(a); if sent by pre-paid first class post or other next working day delivery service, at 9.00 am on the second Business Day after posting; if delivered by commercial courier, on the date and at the time that the courier's delivery receipt is signed; or, if sent by fax or email, one Business Day after transmission.
(c) The provisions of this clause shall not apply to the service of any proceedings or other documents in any legal action.
16.8 Third party rights. No one other than a party to this agreement and their permitted assignees shall have any right to enforce any of its terms.
16.9 Governing law. The Contract, and any dispute or claim arising out of or in connection with it or its subject matter or formation (including non-contractual disputes or claims), shall be governed by, and construed in accordance with the law of England and Wales.
16.10 Jurisdiction. Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim arising out of or in connection with this agreement or its subject matter or formation (including non-contractual disputes or claims).
II. TERMS OF SALE
1.1 In these Terms:
"Buyer" means the person who accepts the Seller's written quotation for the sale of the Goods or whose Written order for the Goods is accepted by the Seller;
"Goods" means the goods (including any instalment of the goods or any parts for them) which the Seller is to supply in accordance with these Terms;
"Seller" means Innovative ThermoAnalytic Instruments Limited (registered in England and Wales under company number 07425277);
"Contract" means the contract for the sale and purchase of the Goods;
"INCOTERMS" means the international rules for the interpretation of trade terms of the International Chamber of Commerce as in force at the date when the Contract is made;
"Terms" means the standard terms of sale set out in this document and (unless the context otherwise requires) includes any special terms agreed in Writing between the Buyer and the Seller;
"Writing" and any similar expression, includes facsimile transmission, electronic mail or other forms of electronic communication, but not text messages or other forms of electronic communication.
1.2 A reference in these Terms to a provision of a statute shall be construed as a reference to that provision as amended, re-enacted or extended at the relevant time.
1.3 The headings in these Terms are for convenience only and shall not affect their interpretation.
2 Basis of the sale
2.1 The Seller shall sell and the Buyer shall purchase the Goods in accordance with the Seller's Written quotation (if accepted by the Buyer), or the Buyer's Written order (if accepted by the Seller), subject in either case to these Terms, which shall govern the Contract to the exclusion of any other terms subject to which any such quotation is accepted or purported to be accepted, or any such order is made or purported to be made, by the Buyer.
2.2 No variation to these Terms shall be binding unless agreed in ‘Writing’ between the authorised representatives of the Buyer and the Seller.
2.3 The Seller's employees or agents are not authorised to make any representations concerning the Goods unless confirmed by the Seller in Writing. In entering into the Contract the Buyer acknowledges that it does not rely on any such representations which are not so confirmed, but nothing in these Terms affects the liability of either party for fraudulent misrepresentation.
2.4 Any advice or recommendation given by the Seller or its employees or agents to the Buyer or its employees or agents as to the storage, application or use of the Goods which is not confirmed in Writing by the Seller is followed or acted on entirely at the Buyer's own risk, and accordingly the Seller shall not be liable for any such advice or recommendation which is not so confirmed.
2.5 Any typographical, clerical or other error or omission in any sales literature, quotation, price list, acceptance of offer, invoice or other document or information issued by the Seller shall be subject to correction without any liability on the part of the Seller.
3 Orders and specifications
3.1 No order submitted by the Buyer shall be deemed to be accepted by the Seller unless and until confirmed in Writing by the Seller's authorised representative.
3.2 The Buyer shall be responsible to the Seller for ensuring the accuracy of the terms of any order (including any applicable specification) submitted by the Buyer, and for giving the Seller any necessary information relating to the Goods within a sufficient time to enable the Seller to perform the Contract in accordance with its terms.
3.3 The quantity, quality and description of the Goods and any specification for them shall be as set out in the Seller's quotation (if accepted by the Buyer) or the Buyer's order (if accepted by the Seller).
3.4 If the Goods are to be manufactured or any process is to be applied to the Goods by the Seller in accordance with a drawing, design or specification submitted by the Buyer, the Buyer shall indemnify the Seller against all loss, damages, costs and expenses awarded against or incurred by the Seller in connection with, or paid or agreed to be paid by the Seller in settlement of, any claim for infringement of any patent, copyright, design, trade mark or other industrial or intellectual property rights of any other person which results from the Seller's use of the Buyer's drawing, design or specification.
3.5 The Seller reserves the right to make any changes in the specification of the Goods which are required to conform with any applicable statutory or EU requirements or, where the Goods are to be supplied to the Seller's specification, which do not materially affect their quality or performance.
3.6 No order which has been accepted by the Seller may be cancelled by the Buyer except with the agreement in Writing of the Seller and on terms that the Buyer shall indemnify the Seller in full against all loss (including loss of profit), costs (including the cost of all labour and materials used), damages, charges and expenses incurred by the Seller as a result of cancellation.
4 Price of the goods
4.1 The price of the Goods shall be the Seller's quoted price or, where no price has been quoted (or a quoted price is no longer valid), the price listed in the Seller's published price list current at the date of acceptance of the order. Where the Goods are supplied for export from the United Kingdom, the Seller's published export price list shall apply. Unless otherwise agreed by the Seller in Writing, all prices quoted are valid for 30 days only or until earlier acceptance by the Buyer, after which time they may be altered by the Seller without giving notice to the Buyer.
4.2 The Seller reserves the right, by giving Written notice to the Buyer at any time before delivery, to increase the price of the Goods to reflect any increase in the cost to the Seller which is due to any factor beyond the control of the Seller (such as, without limitation, any foreign exchange fluctuation, currency regulation, alteration of duties, significant increase in the costs of labour, materials or other costs of manufacture), any change in delivery dates, quantities or specifications for the Goods which is requested by the Buyer, or any delay caused by any instructions of the Buyer or failure of the Buyer to give the Seller adequate information or instructions.
4.3 Except as otherwise stated in the Seller's Written quotation or in any price list of the Seller, and unless otherwise agreed in Writing between the Buyer and the Seller, all prices are given by the Seller on an ex works basis, and where the Seller agrees to deliver the Goods otherwise than at the Seller's premises, the Buyer shall be liable to pay the Seller's charges for transport, packaging and insurance.
4.4 The price is exclusive of any applicable value added tax, which the Buyer shall be additionally liable to pay to the Seller.
4.5 The cost of pallets and returnable containers will be charged to the Buyer in addition to the price of the Goods, but full credit will be given to the Buyer provided they are returned undamaged to the Seller before the due payment date.
5 Terms of payment
5.1 Subject to any special terms agreed in Writing between the Buyer and the Seller, the Seller may invoice the Buyer for the price of the Goods on or at any time after delivery of the Goods, unless the Goods are to be collected by the Buyer or the Buyer wrongfully fails to take delivery of the Goods, in which event the Seller shall be entitled to invoice the Buyer for the price at any time after the Seller has notified the Buyer that the Goods are ready for collection or (as the case may be) the Seller has tendered delivery of the Goods.
5.2 The Buyer shall pay the price of the Goods (less any discount to which the Buyer is entitled, but without any other deduction) within 30 days of the date of the Seller's invoice, and the Seller shall be entitled to recover the price, notwithstanding that delivery may not have taken place and the property in the Goods has not passed to the Buyer. The time of payment of the price shall be of the essence of the Contract. Receipts for payment will be issued only on request.
5.3 If the Buyer fails to make any payment on the due date then, without limiting any other right or remedy available to the Seller, the Seller may:
5.3.1 cancel the contract or suspend any further deliveries to the Buyer;
5.3.2 appropriate any payment made by the Buyer to such of the Goods (or the goods supplied under any other contract between the Buyer and the Seller) as the Seller may think fit (notwithstanding any purported appropriation by the Buyer); and
5.3.3 charge the Buyer interest (both before and after any judgment) on the amount unpaid, at the rate of 4 per cent per annum above base rate of the Bank of England from time to time, until payment in full is made (a part of a month being treated as a full month for the purpose of calculating interest).
6.1 Delivery of the Goods shall be made Ex Works (EXW) by the Buyer collecting the Goods at the Seller's premises at any time after the Seller has notified the Buyer that the Goods are ready for collection or, if some other place for delivery is agreed by the Seller, by the Seller delivering the Goods to that place.
6.2 Any dates quoted for delivery of the Goods are approximate only and the Seller shall not be liable for any delay in delivery of the Goods however caused. Time for delivery shall not be of the essence of the Contract unless previously agreed by the Seller in Writing. The Goods may be delivered by the Seller in advance of the quoted delivery date on giving reasonable notice to the Buyer.
6.3 Where delivery of the Goods is to be made by the Seller in bulk, the Seller reserves the right to deliver up to 5% per cent more or 5% per cent less than the quantity ordered without any adjustment in the price, and the quantity so delivered shall be deemed to be the quantity ordered.
6.4 Where the Goods are to be delivered in instalments, each delivery shall constitute a separate contract and failure by the Seller to deliver any one or more of the instalments in accordance with these Terms or any claim by the Buyer in respect of any one or more instalments shall not entitle the Buyer to treat the Contract as a whole as repudiated.
6.5 If the Seller fails to deliver the Goods (or any instalment) for any reason other than any cause beyond the Seller's reasonable control or the Buyer's fault, and the Seller is accordingly liable to the Buyer, the Seller's liability shall be limited to the excess (if any) of the cost to the Buyer (in the cheapest available market) of similar goods to replace those not delivered over the price of the Goods.
6.6 If the Buyer fails to take delivery of the Goods or fails to give the Seller adequate delivery instructions at the time stated for delivery (otherwise than by reason of any cause beyond the Buyer's reasonable control or by reason of the Seller's fault) then, without limiting any other right or remedy available to the Seller, the Seller may:
6.6.1 store the Goods until actual delivery and charge the Buyer for the reasonable costs (including insurance) of storage; or
6.6.2 sell the Goods at the best price readily obtainable and (after deducting all reasonable storage and selling expenses) account to the Buyer for the excess over the price under the Contract or charge the Buyer for any shortfall below the price under the Contract.
7 Risk and property
7.1 Risk of damage to or loss of the Goods shall pass to the Buyer:
7.1.1 in the case of Goods to be delivered at the Seller's premises, at the time when the Seller notifies the Buyer that the Goods are available for collection; or
7.1.2 in the case of Goods to be delivered otherwise than at the Seller's premises, at the time of delivery or, if the Buyer wrongfully fails to take delivery of the Goods, the time when the Seller has tendered delivery of the Goods.
7.2 Notwithstanding delivery and the passing of risk in the Goods, or any other provision of these Terms, the property in the Goods shall not pass to the Buyer until the Seller has received payment in full of the price of the Goods and all other goods agreed to be sold by the Seller to the Buyer for which payment is then due.
7.3 Until such time as the property in the Goods passes to the Buyer, the Buyer shall hold the Goods as the Seller's fiduciary agent and bailee, and shall keep the Goods separate from those of the Buyer and third parties and properly stored, protected and insured and identified as the Seller's property. The Buyer may resell or use the Goods in the ordinary course of its business, but this right shall cease automatically on the occurrence of any of the events referred to in clause 0.
7.4 Until such time as the property in the Goods passes to the Buyer (and provided the Goods are still in existence and have not been resold), the Seller may at any time require the Buyer to deliver up the Goods to the Seller and, if the Buyer fails to do so forthwith, enter on any premises of the Buyer or any third party where the Goods are stored and repossess the Goods.
7.5 The Buyer shall not be entitled to pledge, create a lien over or in any way charge by way of security for any indebtedness any of the Goods which remain the property of the Seller, but if the Buyer does so all moneys owing by the Buyer to the Seller shall (without limiting any other right or remedy of the Seller) forthwith become due and payable.
8 Warranties and liability
8.1 Subject to the following provisions, the Seller warrants that the Goods will correspond with their specification at the time of delivery and will be free from defects in material and workmanship for a period of 12 months from delivery.
8.2 The above warranty is given by the Seller subject to the following conditions:
8.2.1 the Seller shall be under no liability in respect of any defect in the Goods arising from any drawing, design or specification supplied by the Buyer;
8.2.2 the Seller shall be under no liability in respect of any defect arising from fair wear and tear, wilful damage, negligence, abnormal working conditions, failure to follow the Seller's instructions (whether oral or in Writing), misuse or alteration or repair of the Goods without the Seller's approval;
8.2.3 the Seller shall be under no liability under the above warranty (or any other warranty, condition or guarantee) if the total price for the Goods has not been paid by the due date for payment.
8.3 The above warranty does not extend to parts, materials or equipment not manufactured by the Seller, in respect of which the Buyer shall only be entitled to the benefit of any such warranty or guarantee as is given by the manufacturer to the Seller.
8.4 Subject as expressly provided in these Terms, all warranties, conditions or other terms implied by statute or common law are excluded to the fullest extent permitted by law.
8.5 A claim by the Buyer which is based on any defect in the quality or condition of the Goods or their failure to correspond with specification shall (whether or not delivery is refused by the Buyer) be notified to the Seller within seven days from the date of delivery or (where the defect or failure was not apparent on reasonable inspection) within a reasonable time after discovery of the defect or failure. If delivery is not refused, and the Buyer does not notify the Seller accordingly, the Buyer shall not be entitled to reject the Goods and the Seller shall have no liability for such defect or failure, and the Buyer shall be bound to pay the price as if the Goods had been delivered in accordance with the Contract.
8.6 Where a valid claim in respect of any of the Goods which is based on a defect in the quality or condition of the Goods or their failure to meet specification is notified to the Seller in accordance with these Terms, the Seller may replace the Goods (or the part in question) free of charge or, at the Seller's sole discretion, refund to the Buyer the price of the Goods (or a proportionate part of the price), in which case the Seller shall have no further liability to the Buyer.
8.7 Except in of the case of liability for death or personal injury caused by the Seller's negligence, liability for defective products under the Consumer Protection Act 1987 or liability under section 12 of the Sale of Goods Act 1979, the Seller shall not be liable to the Buyer by reason of any representation (unless fraudulent), or any implied warranty, condition or other term, or any duty at common law, or under the express terms of the Contract, for loss of profit or for any indirect, special or consequential loss or damage, costs, expenses or other claims for compensation whatsoever (whether caused by the negligence of the Seller, its employees or agents or otherwise) which arise out of or in connection with the supply of the Goods (including any delay in supplying or any failure to supply the Goods in accordance with the Contract or at all) or their use or resale by the Buyer, and the entire liability of the Seller under or in connection with the Contract shall not exceed the price of the Goods, except as expressly provided in these Terms.
8.8 The Seller shall not be liable to the Buyer or be deemed to be in breach of the Contract by reason of any delay in performing, or any failure to perform, any of the Seller's obligations in relation to the Goods, if the delay or failure was due to any cause beyond the Seller's reasonable control. Without limiting the foregoing, the following shall be regarded as causes beyond the Seller's reasonable control:
8.8.1 Act of God, explosion, flood, tempest, fire or accident;
8.8.2 war or threat of war, sabotage, insurrection, civil disturbance or requisition;
8.8.3 acts, restrictions, regulations, bye-laws, prohibitions or measures of any kind on the part of any governmental, parliamentary or local authority;
8.8.4 import or export regulations or embargoes;
8.8.5 strikes, lock-outs or other industrial actions or trade disputes (whether involving employees of the Seller or of a third party);
8.8.6 difficulties in obtaining raw materials, labour, fuel, parts or machinery;
8.8.7 power failure or breakdown in machinery.
9.1 If a claim (actual or threatened) is made against the Buyer that the Goods infringe or that their use or resale infringes the patent, copyright, design, trade mark or other industrial or intellectual property rights of any other person, then unless the claim arises from the use of a drawing, design or specification supplied by the Buyer, the Seller shall indemnify the Buyer against all loss, damages, costs and expenses awarded against or incurred by the Buyer in connection with the claim, or paid or agreed to be paid by the Buyer in settlement of the claim, provided that:
9.1.1 the Seller is given full control of any proceedings or negotiations in connection with the claim;
9.1.2 the Buyer shall give the Seller all reasonable assistance for the purposes of any such proceedings or negotiations;
9.1.3 except pursuant to a final award, the Buyer shall not pay or accept the claim, or compromise any such proceedings without the consent of the Seller (which shall not be unreasonably withheld);
9.1.4 the Buyer shall do nothing which would or might vitiate any policy of insurance or insurance cover which the Buyer may have in relation to such infringement, and this indemnity shall not apply to the extent that the Buyer recovers any sums under any such policy or cover (which the Buyer shall use its best endeavours to do);
9.1.5 the Seller shall be entitled to the benefit of, and the Buyer shall accordingly account to the Seller for, all damages and costs (if any) awarded in favour of the Buyer which are payable by, or agreed with the consent of the Buyer (which consent shall not be unreasonably withheld) to be paid by, any other party in respect of any such claim; and
9.1.6 without limiting any duty of the Buyer at common law, the Seller may require the Buyer to take such steps as the Seller may reasonably require to mitigate or reduce any such loss, damages, costs or expenses for which the Seller is liable to indemnify the Buyer under this clause.
10 Insolvency of buyer
10.1 This clause 10 applies if:
10.1.1 the Buyer makes a composition or voluntary arrangement with its creditors or (being an individual or firm) becomes bankrupt or (being a company) enters administration or goes into liquidation (otherwise than for the purposes of amalgamation or reconstruction), or a moratorium comes into force in respect of the Buyer (within the meaning of the Insolvency Act 1986; or
10.1.2 an encumbrancer takes possession, or a receiver is appointed, of any of the property or assets of the Buyer; or
10.1.3 the Buyer ceases, or threatens to cease, to carry on business; or
10.1.4 the Seller reasonably apprehends that any of the events mentioned above is about to occur in relation to the Buyer and notifies the Buyer accordingly.
10.2 If this clause applies then, without limiting any other right or remedy available to the Seller, the Seller may cancel the Contract or suspend any further deliveries under the Contract without any liability to the Buyer, and if the Goods have been delivered but not paid for the price shall become immediately due and payable notwithstanding any previous agreement or arrangement to the contrary.
11 Export terms
11.1 Unless the context otherwise requires, any term or expression which is defined in or given a particular meaning by the provisions of “INCOTERMS” shall have the same meaning in these Terms, but if there is any conflict between the provisions of INCOTERMS and these Terms, the latter shall prevail.
11.2 Where the Goods are supplied for export from the United Kingdom, the provisions of this clause 11 shall (subject to any special terms agreed in Writing between the Buyer and the Seller) apply notwithstanding any other provision of these Terms.
11.3 The Buyer shall be responsible for complying with any legislation or regulations governing the importation of the Goods into the country of destination and for the payment of any duties on them.
11.4 Unless otherwise agreed in Writing between the Buyer and the Seller, the Goods shall be delivered fob the air or sea port of shipment and the Seller shall be under no obligation to give notice under section 32(3) of the Sale of Goods Act 1979.
11.5 The Buyer shall be responsible for arranging for testing and inspection of the Goods at the Seller's premises before shipment. The Seller shall have no liability for any claim in respect of any defect in the Goods which would be apparent on inspection and which is made after shipment, or in respect of any damage during transit.
11.6 Unless otherwise required by the Seller, payment of all amounts due to the Seller shall be made by an irrevocable letter of credit, in a form acceptable to the Seller, to be opened by the Buyer in favour of the Seller and confirmed by a bank in the United Kingdom acceptable to the Seller within 14 days after the Contract is concluded.
11.7 The Buyer shall not offer the Goods for resale in any other country notified by the Seller to the Buyer at or before the time the Buyer's order is placed, or sell the Goods to any person if the Buyer knows or has reason to believe that that person intends to resell the Goods in any such country.
12.1 A notice required or permitted to be given by either party to the other under these Terms shall be in Writing addressed to that other party at its registered office or principal place of business or such other address as may at the relevant time have been notified pursuant to this provision to the party giving the notice.
12.2 No waiver by the Seller of any breach of the Contract by the Buyer shall be considered as a waiver of any subsequent breach of the same or any other provision.
12.3 If any provision of the Contract is held by a court or other competent authority to be invalid or unenforceable in whole or in part the validity of the other provisions of the Contract and the remainder of the provision in question shall not be affected.
12.4 Any dispute arising under or in connection with the Contract or the sale of the Goods shall be governed by and construed in accordance with the law of England and Wales.
12.5 The Seller and Buyer irrevocably agree that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.
Version: January 2017